{"id":6252,"date":"2018-03-07T09:27:01","date_gmt":"2018-03-07T09:27:01","guid":{"rendered":""},"modified":"2019-06-21T14:41:01","modified_gmt":"2019-06-21T14:41:01","slug":"trustees-of-ampleforth-abbey-v-turner","status":"publish","type":"post","link":"https:\/\/www.lawteacher.net\/cases\/trustees-of-ampleforth-abbey-v-turner.php","title":{"rendered":"Trustees of Ampleforth Abbey v Turner &#038; Townsend"},"content":{"rendered":"<p><strong>Trustees of Ampleforth Abbey Trust v Turner &#038; Townsend Management Ltd [2012] EWHC 2137<\/strong><\/p>\n<p>        Whether a duty of care was owed by a project manager to an employer in respect of ensuring that a contract containing a liquidated damages clause was agreed with a contractor<\/p>\n<p>        <strong><u>Facts<\/u><\/strong><\/p>\n<p>        The claimant employed the defendant to project manage the building of three construction projects on its property. The works were carried out by a contractor and were completed to a satisfactory standard, but significantly later than the claimant had envisaged. The contractor stated that it was entitled to an extension of time. The works were carried out under letters of intent, with the contract only being agreed through mediation after the works were complete. The contract contained a clause limiting the claimant\u2019s ability to claim for delay. The claimant sought damages against the defendant on the basis that the defendant had failed to exercise reasonable care and skill in the exercise of the build and procurement process from the contractor and that this failure had caused the claimant loss.<\/p>\n<p>        <strong><u>Issue<\/u><\/strong><\/p>\n<p>        The issue in this context was whether the defendant owed a duty of care to the claimant in respect of ensuring that it was entitled to liquidated damages for delay in the agreement with the contractor.<\/p>\n<p>        <strong><u>Held<\/u><\/strong><\/p>\n<p>        It was held that the defendant did owe a duty of care to the claimant and had failed in that duty by failing to exert sufficient pressure on the contractor to finalise the contract. The breach caused loss because if there was no breach the claimant would have taken steps to ensure that it was entitled to liquidated damages and there was a real possibility that the contractor would have agreed to those terms.<\/p>\n","protected":false},"excerpt":{"rendered":"<p>The claimant employed the defendant to project manage the building of three construction projects on its property. The works were carried out&#8230;<\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"closed","ping_status":"closed","sticky":false,"template":"","format":"standard","meta":{"footnotes":""},"categories":[2],"tags":[85],"class_list":["post-6252","post","type-post","status-publish","format-standard","hentry","category-cases","tag-uk-law"],"yoast_head":"<!-- This site is optimized with the Yoast SEO Premium plugin v26.6 (Yoast SEO v26.6) - https:\/\/yoast.com\/wordpress\/plugins\/seo\/ -->\n<title>Trustees of Ampleforth Abbey v Turner &amp; Townsend | LawTeacher.net<\/title>\n<meta name=\"description\" content=\"The claimant employed the defendant to project manage the building of three construction projects on its property. The works were carried out...\" \/>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.lawteacher.net\/cases\/trustees-of-ampleforth-abbey-v-turner.php\" \/>\n<meta property=\"og:locale\" content=\"en_GB\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"Trustees of Ampleforth Abbey v Turner &amp; Townsend\" \/>\n<meta property=\"og:description\" content=\"The claimant employed the defendant to project manage the building of three construction projects on its property. The works were carried out...\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.lawteacher.net\/cases\/trustees-of-ampleforth-abbey-v-turner.php\" \/>\n<meta property=\"og:site_name\" content=\"LawTeacher.net\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/LawTeacherNet\/\" \/>\n<meta property=\"article:author\" content=\"https:\/\/www.facebook.com\/LawTeacherNet\" \/>\n<meta property=\"article:published_time\" content=\"-0001-11-30T00:00:00+00:00\" \/>\n<meta property=\"og:image\" content=\"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-large-logo.webp\" \/>\n\t<meta property=\"og:image:width\" content=\"1920\" \/>\n\t<meta property=\"og:image:height\" content=\"1080\" \/>\n\t<meta property=\"og:image:type\" content=\"image\/webp\" \/>\n<meta name=\"author\" content=\"LawTeacher\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@LawTeacherNet\" \/>\n<meta name=\"twitter:site\" content=\"@LawTeacherNet\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"LawTeacher\" \/>\n\t<meta name=\"twitter:label2\" content=\"Estimated reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"1 minute\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"ScholarlyArticle\",\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php#article\",\"isPartOf\":{\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php\"},\"author\":{\"name\":\"LawTeacher\",\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/person\/b99962c073c877c4ab8ee3d2486cd56e\"},\"headline\":\"Trustees of Ampleforth Abbey v Turner &#038; Townsend\",\"datePublished\":\"-0001-11-30T00:00:00+00:00\",\"mainEntityOfPage\":{\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php\"},\"wordCount\":292,\"publisher\":{\"@id\":\"https:\/\/wp.lawteacher.net\/#organization\"},\"keywords\":[\"UK Law\"],\"articleSection\":[\"Case Summaries\"],\"inLanguage\":\"en-GB\"},{\"@type\":\"WebPage\",\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php\",\"url\":\"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php\",\"name\":\"Trustees of Ampleforth Abbey v Turner & Townsend | LawTeacher.net\",\"isPartOf\":{\"@id\":\"https:\/\/wp.lawteacher.net\/#website\"},\"datePublished\":\"-0001-11-30T00:00:00+00:00\",\"description\":\"The claimant employed the defendant to project manage the building of three construction projects on its property. The works were carried out...\",\"breadcrumb\":{\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php#breadcrumb\"},\"inLanguage\":\"en-GB\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php\"]}]},{\"@type\":\"BreadcrumbList\",\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php#breadcrumb\",\"itemListElement\":[{\"@type\":\"ListItem\",\"position\":1,\"name\":\"Home\",\"item\":\"https:\/\/wp.lawteacher.net\/\"},{\"@type\":\"ListItem\",\"position\":2,\"name\":\"Trustees of Ampleforth Abbey v Turner &#038; Townsend\"}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/wp.lawteacher.net\/#website\",\"url\":\"https:\/\/wp.lawteacher.net\/\",\"name\":\"Law Teacher\",\"description\":\"The Law Essay Professionals\",\"publisher\":{\"@id\":\"https:\/\/wp.lawteacher.net\/#organization\"},\"alternateName\":\"LawTeacher.net\",\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/wp.lawteacher.net\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-GB\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/wp.lawteacher.net\/#organization\",\"name\":\"Law Teacher\",\"alternateName\":\"LawTeacher.net\",\"url\":\"https:\/\/wp.lawteacher.net\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-GB\",\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-logo.jpg\",\"contentUrl\":\"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-logo.jpg\",\"width\":250,\"height\":250,\"caption\":\"Law Teacher\"},\"image\":{\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/LawTeacherNet\/\",\"https:\/\/x.com\/LawTeacherNet\",\"https:\/\/api.whatsapp.com\/send\/?phone=447723491966&text&type=phone_number&app_absent=0\"],\"description\":\"Law Teacher provides academic writing services for law students throughout the world.\",\"email\":\"contact@lawteacher.net\",\"telephone\":\"+44 115 966 7966\",\"numberOfEmployees\":{\"@type\":\"QuantitativeValue\",\"minValue\":\"51\",\"maxValue\":\"200\"}},{\"@type\":\"Person\",\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/person\/b99962c073c877c4ab8ee3d2486cd56e\",\"name\":\"LawTeacher\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-GB\",\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/4fdfab0a9ef25209f111018ecc8a983e19e57c5066a9277217a119582ccbeed3?s=96&d=mm&r=g\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/4fdfab0a9ef25209f111018ecc8a983e19e57c5066a9277217a119582ccbeed3?s=96&d=mm&r=g\",\"caption\":\"LawTeacher\"},\"description\":\"LawTeacher.net is the UK's leading provider of academic legal support, offering both writing services and an extensive collection of law study resources for students in the UK and overseas. Founded in 2003 by Grey's Inn graduate Barclay Littlewood, the Company was built on a commitment to excellence, with unique guarantees and a high standard of service from day one. The team includes over 500 UK legally qualified writing experts, with many practising solicitors and barristers, and several former lecturers.\",\"sameAs\":[\"https:\/\/www.lawteacher.net\",\"https:\/\/www.facebook.com\/LawTeacherNet\",\"https:\/\/x.com\/LawTeacherNet\",\"https:\/\/gravatar.com\/lawteacherprofile\"],\"knowsAbout\":[\"Contract Law\",\"Criminal Law\",\"Constitutional and Administrative Law\",\"EU Law\",\"Tort Law\",\"Property Law\",\"Equity and Trusts\",\"Jurisprudence\",\"Company Law\",\"Commercial Law\",\"Family Law\",\"Human Rights Law\",\"Employment Law\",\"Evidence\",\"Public International Law\",\"Legal Research and Methods\",\"Dispute Resolution\",\"Business Law and Practice\",\"Civil Litigation\",\"Criminal Litigation\",\"Professional Conduct\",\"Taxation\",\"Wills and Administration of Estates\",\"Solicitors\u2019 Accounts\"],\"url\":\"https:\/\/www.lawteacher.net\/author\/lawteacher\"}]}<\/script>\n<!-- \/ Yoast SEO Premium plugin. -->","yoast_head_json":{"title":"Trustees of Ampleforth Abbey v Turner & Townsend | LawTeacher.net","description":"The claimant employed the defendant to project manage the building of three construction projects on its property. The works were carried out...","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.lawteacher.net\/cases\/trustees-of-ampleforth-abbey-v-turner.php","og_locale":"en_GB","og_type":"article","og_title":"Trustees of Ampleforth Abbey v Turner & Townsend","og_description":"The claimant employed the defendant to project manage the building of three construction projects on its property. The works were carried out...","og_url":"https:\/\/www.lawteacher.net\/cases\/trustees-of-ampleforth-abbey-v-turner.php","og_site_name":"LawTeacher.net","article_publisher":"https:\/\/www.facebook.com\/LawTeacherNet\/","article_author":"https:\/\/www.facebook.com\/LawTeacherNet","article_published_time":"-0001-11-30T00:00:00+00:00","og_image":[{"width":1920,"height":1080,"url":"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-large-logo.webp","type":"image\/webp"}],"author":"LawTeacher","twitter_card":"summary_large_image","twitter_creator":"@LawTeacherNet","twitter_site":"@LawTeacherNet","twitter_misc":{"Written by":"LawTeacher","Estimated reading time":"1 minute"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"ScholarlyArticle","@id":"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php#article","isPartOf":{"@id":"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php"},"author":{"name":"LawTeacher","@id":"https:\/\/wp.lawteacher.net\/#\/schema\/person\/b99962c073c877c4ab8ee3d2486cd56e"},"headline":"Trustees of Ampleforth Abbey v Turner &#038; Townsend","datePublished":"-0001-11-30T00:00:00+00:00","mainEntityOfPage":{"@id":"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php"},"wordCount":292,"publisher":{"@id":"https:\/\/wp.lawteacher.net\/#organization"},"keywords":["UK Law"],"articleSection":["Case Summaries"],"inLanguage":"en-GB"},{"@type":"WebPage","@id":"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php","url":"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php","name":"Trustees of Ampleforth Abbey v Turner & Townsend | LawTeacher.net","isPartOf":{"@id":"https:\/\/wp.lawteacher.net\/#website"},"datePublished":"-0001-11-30T00:00:00+00:00","description":"The claimant employed the defendant to project manage the building of three construction projects on its property. The works were carried out...","breadcrumb":{"@id":"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php#breadcrumb"},"inLanguage":"en-GB","potentialAction":[{"@type":"ReadAction","target":["http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php"]}]},{"@type":"BreadcrumbList","@id":"http:\/\/64.226.118.242:8001\/cases\/trustees-of-ampleforth-abbey-v-turner.php#breadcrumb","itemListElement":[{"@type":"ListItem","position":1,"name":"Home","item":"https:\/\/wp.lawteacher.net\/"},{"@type":"ListItem","position":2,"name":"Trustees of Ampleforth Abbey v Turner &#038; Townsend"}]},{"@type":"WebSite","@id":"https:\/\/wp.lawteacher.net\/#website","url":"https:\/\/wp.lawteacher.net\/","name":"Law Teacher","description":"The Law Essay Professionals","publisher":{"@id":"https:\/\/wp.lawteacher.net\/#organization"},"alternateName":"LawTeacher.net","potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/wp.lawteacher.net\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-GB"},{"@type":"Organization","@id":"https:\/\/wp.lawteacher.net\/#organization","name":"Law Teacher","alternateName":"LawTeacher.net","url":"https:\/\/wp.lawteacher.net\/","logo":{"@type":"ImageObject","inLanguage":"en-GB","@id":"https:\/\/wp.lawteacher.net\/#\/schema\/logo\/image\/","url":"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-logo.jpg","contentUrl":"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-logo.jpg","width":250,"height":250,"caption":"Law Teacher"},"image":{"@id":"https:\/\/wp.lawteacher.net\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/LawTeacherNet\/","https:\/\/x.com\/LawTeacherNet","https:\/\/api.whatsapp.com\/send\/?phone=447723491966&text&type=phone_number&app_absent=0"],"description":"Law Teacher provides academic writing services for law students throughout the world.","email":"contact@lawteacher.net","telephone":"+44 115 966 7966","numberOfEmployees":{"@type":"QuantitativeValue","minValue":"51","maxValue":"200"}},{"@type":"Person","@id":"https:\/\/wp.lawteacher.net\/#\/schema\/person\/b99962c073c877c4ab8ee3d2486cd56e","name":"LawTeacher","image":{"@type":"ImageObject","inLanguage":"en-GB","@id":"https:\/\/wp.lawteacher.net\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/4fdfab0a9ef25209f111018ecc8a983e19e57c5066a9277217a119582ccbeed3?s=96&d=mm&r=g","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/4fdfab0a9ef25209f111018ecc8a983e19e57c5066a9277217a119582ccbeed3?s=96&d=mm&r=g","caption":"LawTeacher"},"description":"LawTeacher.net is the UK's leading provider of academic legal support, offering both writing services and an extensive collection of law study resources for students in the UK and overseas. Founded in 2003 by Grey's Inn graduate Barclay Littlewood, the Company was built on a commitment to excellence, with unique guarantees and a high standard of service from day one. The team includes over 500 UK legally qualified writing experts, with many practising solicitors and barristers, and several former lecturers.","sameAs":["https:\/\/www.lawteacher.net","https:\/\/www.facebook.com\/LawTeacherNet","https:\/\/x.com\/LawTeacherNet","https:\/\/gravatar.com\/lawteacherprofile"],"knowsAbout":["Contract Law","Criminal Law","Constitutional and Administrative Law","EU Law","Tort Law","Property Law","Equity and Trusts","Jurisprudence","Company Law","Commercial Law","Family Law","Human Rights Law","Employment Law","Evidence","Public International Law","Legal Research and Methods","Dispute Resolution","Business Law and Practice","Civil Litigation","Criminal Litigation","Professional Conduct","Taxation","Wills and Administration of Estates","Solicitors\u2019 Accounts"],"url":"https:\/\/www.lawteacher.net\/author\/lawteacher"}]}},"_links":{"self":[{"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/posts\/6252","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/comments?post=6252"}],"version-history":[{"count":0,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/posts\/6252\/revisions"}],"wp:attachment":[{"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/media?parent=6252"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/categories?post=6252"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/tags?post=6252"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}