Davis Contractors Ltd v Fareham Urban District Council [1956] AC 696; [1956] 3 WLR 37; [1956] 2 All ER 145; 54 LGR 289; (1956) 100 SJ 378;<\/strong><\/p>\nCONTRACT, IMPOSSIBILITY TO PERFORM A CONTRACT ON TIME, DELAY NOT DUE TO FAULT OF EITHER PARTY, LABOUR SHORTAGE, FRUSTRATION OF A CONTRACT, TENDER, INCORPORATION IN A CONTRACT, QUANTUM MERUIT<\/p>\n
Facts<\/h3>\n
The appellants tendered for a contract with the respondents to build 28 houses for 8 months. The tender was accompanied by a letter which stated that the tender was subject to adequate supplies of materials and labour when required to carry out the work within the time specified. Later, the appellants entered into a contract with the respondents to build the houses at a fixed price, subject to certain adjustments. The contract incorporated a number of preliminary documents, listed in a clause. The tender was specified to be one of them, but the letter was not.<\/p>\n
Due mainly to the lack of skilled labour, the work took 22, instead of 8 months. The appellants were paid the fixed price, plus the stipulated increases and adjustments. However, they claimed that they were entitled to more money on the basis of quantum meruit<\/em>. The appellants also argued that the price in the contract was not binding either because it was subject to an overriding condition contained in the letter, or due to the delay in the performance of the contract due to the shortage of labour which frustrated the contract.<\/p>\nIssues<\/h3>\n
(1) Are the appellants entitled to more money on the basis of quantum meruit<\/em>?<\/p>\n(2) Was the contract overridden by the letter in the tender?<\/p>\n
(3) Was the contract frustrated due the shortage of labour that caused a long delay in the performance of the contract?<\/p>\n
Decision\/Outcome<\/h3>\n
The appeal was dismissed.<\/p>\n
The appellants are not entitled to be paid more money on the basis of quantum meruit<\/em> as:<\/p>\n(1) The letter in the tender and the condition which it stipulated were not incorporated in the contract.<\/p>\n
(2) The fact that the two parties expected that the work could be finished within eight months did not result in the contract being frustrated when it turned out that it could not be performed within the specified time.<\/p>\n","protected":false},"excerpt":{"rendered":"
The appellants tendered for a contract with the respondents to build 28 houses for 8 months. The tender was accompanied by a letter which stated that the tender was subject to adequate supplies of materials and labour when required to carry out the work within the time specified.<\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"closed","ping_status":"closed","sticky":false,"template":"","format":"standard","meta":{"footnotes":""},"categories":[2],"tags":[85],"class_list":["post-5506","post","type-post","status-publish","format-standard","hentry","category-cases","tag-uk-law"],"yoast_head":"\n
Davis Contractors Ltd v Fareham Urban District Council | LawTeacher.net<\/title>\n<meta name=\"description\" content=\"The appellants tendered for a contract with the respondents to build 28 houses for 8 months. The tender was accompanied by a letter which stated that the tender was subject to adequate supplies of materials and labour when required to carry out the work within the time specified.\" \/>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.lawteacher.net\/cases\/davis-contractors-v-fareham-urban-dc.php\" \/>\n<meta property=\"og:locale\" content=\"en_GB\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"Davis Contractors Ltd v Fareham Urban District Council\" \/>\n<meta property=\"og:description\" content=\"The appellants tendered for a contract with the respondents to build 28 houses for 8 months. The tender was accompanied by a letter which stated that the tender was subject to adequate supplies of materials and labour when required to carry out the work within the time specified.\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.lawteacher.net\/cases\/davis-contractors-v-fareham-urban-dc.php\" \/>\n<meta property=\"og:site_name\" content=\"LawTeacher.net\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/LawTeacherNet\/\" \/>\n<meta property=\"article:author\" content=\"https:\/\/www.facebook.com\/LawTeacherNet\" \/>\n<meta property=\"article:published_time\" content=\"-0001-11-30T00:00:00+00:00\" \/>\n<meta property=\"og:image\" content=\"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-large-logo.webp\" \/>\n\t<meta property=\"og:image:width\" content=\"1920\" \/>\n\t<meta property=\"og:image:height\" content=\"1080\" \/>\n\t<meta property=\"og:image:type\" content=\"image\/webp\" \/>\n<meta name=\"author\" content=\"LawTeacher\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@LawTeacherNet\" \/>\n<meta name=\"twitter:site\" content=\"@LawTeacherNet\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"LawTeacher\" \/>\n\t<meta name=\"twitter:label2\" content=\"Estimated reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"2 minutes\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"ScholarlyArticle\",\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php#article\",\"isPartOf\":{\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php\"},\"author\":{\"name\":\"LawTeacher\",\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/person\/b99962c073c877c4ab8ee3d2486cd56e\"},\"headline\":\"Davis Contractors Ltd v Fareham Urban District Council\",\"datePublished\":\"-0001-11-30T00:00:00+00:00\",\"mainEntityOfPage\":{\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php\"},\"wordCount\":361,\"publisher\":{\"@id\":\"https:\/\/wp.lawteacher.net\/#organization\"},\"keywords\":[\"UK Law\"],\"articleSection\":[\"Case Summaries\"],\"inLanguage\":\"en-GB\"},{\"@type\":\"WebPage\",\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php\",\"url\":\"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php\",\"name\":\"Davis Contractors Ltd v Fareham Urban District Council | LawTeacher.net\",\"isPartOf\":{\"@id\":\"https:\/\/wp.lawteacher.net\/#website\"},\"datePublished\":\"-0001-11-30T00:00:00+00:00\",\"description\":\"The appellants tendered for a contract with the respondents to build 28 houses for 8 months. The tender was accompanied by a letter which stated that the tender was subject to adequate supplies of materials and labour when required to carry out the work within the time specified.\",\"breadcrumb\":{\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php#breadcrumb\"},\"inLanguage\":\"en-GB\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php\"]}]},{\"@type\":\"BreadcrumbList\",\"@id\":\"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php#breadcrumb\",\"itemListElement\":[{\"@type\":\"ListItem\",\"position\":1,\"name\":\"Home\",\"item\":\"https:\/\/wp.lawteacher.net\/\"},{\"@type\":\"ListItem\",\"position\":2,\"name\":\"Davis Contractors Ltd v Fareham Urban District Council\"}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/wp.lawteacher.net\/#website\",\"url\":\"https:\/\/wp.lawteacher.net\/\",\"name\":\"Law Teacher\",\"description\":\"The Law Essay Professionals\",\"publisher\":{\"@id\":\"https:\/\/wp.lawteacher.net\/#organization\"},\"alternateName\":\"LawTeacher.net\",\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/wp.lawteacher.net\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-GB\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/wp.lawteacher.net\/#organization\",\"name\":\"Law Teacher\",\"alternateName\":\"LawTeacher.net\",\"url\":\"https:\/\/wp.lawteacher.net\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-GB\",\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-logo.jpg\",\"contentUrl\":\"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-logo.jpg\",\"width\":250,\"height\":250,\"caption\":\"Law Teacher\"},\"image\":{\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/LawTeacherNet\/\",\"https:\/\/x.com\/LawTeacherNet\",\"https:\/\/api.whatsapp.com\/send\/?phone=447723491966&text&type=phone_number&app_absent=0\"],\"description\":\"Law Teacher provides academic writing services for law students throughout the world.\",\"email\":\"contact@lawteacher.net\",\"telephone\":\"+44 115 966 7966\",\"numberOfEmployees\":{\"@type\":\"QuantitativeValue\",\"minValue\":\"51\",\"maxValue\":\"200\"}},{\"@type\":\"Person\",\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/person\/b99962c073c877c4ab8ee3d2486cd56e\",\"name\":\"LawTeacher\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-GB\",\"@id\":\"https:\/\/wp.lawteacher.net\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/4fdfab0a9ef25209f111018ecc8a983e19e57c5066a9277217a119582ccbeed3?s=96&d=mm&r=g\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/4fdfab0a9ef25209f111018ecc8a983e19e57c5066a9277217a119582ccbeed3?s=96&d=mm&r=g\",\"caption\":\"LawTeacher\"},\"description\":\"LawTeacher.net is the UK's leading provider of academic legal support, offering both writing services and an extensive collection of law study resources for students in the UK and overseas. Founded in 2003 by Grey's Inn graduate Barclay Littlewood, the Company was built on a commitment to excellence, with unique guarantees and a high standard of service from day one. The team includes over 500 UK legally qualified writing experts, with many practising solicitors and barristers, and several former lecturers.\",\"sameAs\":[\"https:\/\/www.lawteacher.net\",\"https:\/\/www.facebook.com\/LawTeacherNet\",\"https:\/\/x.com\/LawTeacherNet\",\"https:\/\/gravatar.com\/lawteacherprofile\"],\"knowsAbout\":[\"Contract Law\",\"Criminal Law\",\"Constitutional and Administrative Law\",\"EU Law\",\"Tort Law\",\"Property Law\",\"Equity and Trusts\",\"Jurisprudence\",\"Company Law\",\"Commercial Law\",\"Family Law\",\"Human Rights Law\",\"Employment Law\",\"Evidence\",\"Public International Law\",\"Legal Research and Methods\",\"Dispute Resolution\",\"Business Law and Practice\",\"Civil Litigation\",\"Criminal Litigation\",\"Professional Conduct\",\"Taxation\",\"Wills and Administration of Estates\",\"Solicitors\u2019 Accounts\"],\"url\":\"https:\/\/www.lawteacher.net\/author\/lawteacher\"}]}<\/script>\n<!-- \/ Yoast SEO Premium plugin. -->","yoast_head_json":{"title":"Davis Contractors Ltd v Fareham Urban District Council | LawTeacher.net","description":"The appellants tendered for a contract with the respondents to build 28 houses for 8 months. The tender was accompanied by a letter which stated that the tender was subject to adequate supplies of materials and labour when required to carry out the work within the time specified.","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.lawteacher.net\/cases\/davis-contractors-v-fareham-urban-dc.php","og_locale":"en_GB","og_type":"article","og_title":"Davis Contractors Ltd v Fareham Urban District Council","og_description":"The appellants tendered for a contract with the respondents to build 28 houses for 8 months. The tender was accompanied by a letter which stated that the tender was subject to adequate supplies of materials and labour when required to carry out the work within the time specified.","og_url":"https:\/\/www.lawteacher.net\/cases\/davis-contractors-v-fareham-urban-dc.php","og_site_name":"LawTeacher.net","article_publisher":"https:\/\/www.facebook.com\/LawTeacherNet\/","article_author":"https:\/\/www.facebook.com\/LawTeacherNet","article_published_time":"-0001-11-30T00:00:00+00:00","og_image":[{"width":1920,"height":1080,"url":"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-large-logo.webp","type":"image\/webp"}],"author":"LawTeacher","twitter_card":"summary_large_image","twitter_creator":"@LawTeacherNet","twitter_site":"@LawTeacherNet","twitter_misc":{"Written by":"LawTeacher","Estimated reading time":"2 minutes"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"ScholarlyArticle","@id":"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php#article","isPartOf":{"@id":"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php"},"author":{"name":"LawTeacher","@id":"https:\/\/wp.lawteacher.net\/#\/schema\/person\/b99962c073c877c4ab8ee3d2486cd56e"},"headline":"Davis Contractors Ltd v Fareham Urban District Council","datePublished":"-0001-11-30T00:00:00+00:00","mainEntityOfPage":{"@id":"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php"},"wordCount":361,"publisher":{"@id":"https:\/\/wp.lawteacher.net\/#organization"},"keywords":["UK Law"],"articleSection":["Case Summaries"],"inLanguage":"en-GB"},{"@type":"WebPage","@id":"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php","url":"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php","name":"Davis Contractors Ltd v Fareham Urban District Council | LawTeacher.net","isPartOf":{"@id":"https:\/\/wp.lawteacher.net\/#website"},"datePublished":"-0001-11-30T00:00:00+00:00","description":"The appellants tendered for a contract with the respondents to build 28 houses for 8 months. The tender was accompanied by a letter which stated that the tender was subject to adequate supplies of materials and labour when required to carry out the work within the time specified.","breadcrumb":{"@id":"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php#breadcrumb"},"inLanguage":"en-GB","potentialAction":[{"@type":"ReadAction","target":["http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php"]}]},{"@type":"BreadcrumbList","@id":"http:\/\/64.226.118.242:8001\/cases\/davis-contractors-v-fareham-urban-dc.php#breadcrumb","itemListElement":[{"@type":"ListItem","position":1,"name":"Home","item":"https:\/\/wp.lawteacher.net\/"},{"@type":"ListItem","position":2,"name":"Davis Contractors Ltd v Fareham Urban District Council"}]},{"@type":"WebSite","@id":"https:\/\/wp.lawteacher.net\/#website","url":"https:\/\/wp.lawteacher.net\/","name":"Law Teacher","description":"The Law Essay Professionals","publisher":{"@id":"https:\/\/wp.lawteacher.net\/#organization"},"alternateName":"LawTeacher.net","potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/wp.lawteacher.net\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-GB"},{"@type":"Organization","@id":"https:\/\/wp.lawteacher.net\/#organization","name":"Law Teacher","alternateName":"LawTeacher.net","url":"https:\/\/wp.lawteacher.net\/","logo":{"@type":"ImageObject","inLanguage":"en-GB","@id":"https:\/\/wp.lawteacher.net\/#\/schema\/logo\/image\/","url":"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-logo.jpg","contentUrl":"https:\/\/www.lawteacher.net\/wp-content\/uploads\/2025\/07\/LT-logo.jpg","width":250,"height":250,"caption":"Law Teacher"},"image":{"@id":"https:\/\/wp.lawteacher.net\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/LawTeacherNet\/","https:\/\/x.com\/LawTeacherNet","https:\/\/api.whatsapp.com\/send\/?phone=447723491966&text&type=phone_number&app_absent=0"],"description":"Law Teacher provides academic writing services for law students throughout the world.","email":"contact@lawteacher.net","telephone":"+44 115 966 7966","numberOfEmployees":{"@type":"QuantitativeValue","minValue":"51","maxValue":"200"}},{"@type":"Person","@id":"https:\/\/wp.lawteacher.net\/#\/schema\/person\/b99962c073c877c4ab8ee3d2486cd56e","name":"LawTeacher","image":{"@type":"ImageObject","inLanguage":"en-GB","@id":"https:\/\/wp.lawteacher.net\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/4fdfab0a9ef25209f111018ecc8a983e19e57c5066a9277217a119582ccbeed3?s=96&d=mm&r=g","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/4fdfab0a9ef25209f111018ecc8a983e19e57c5066a9277217a119582ccbeed3?s=96&d=mm&r=g","caption":"LawTeacher"},"description":"LawTeacher.net is the UK's leading provider of academic legal support, offering both writing services and an extensive collection of law study resources for students in the UK and overseas. Founded in 2003 by Grey's Inn graduate Barclay Littlewood, the Company was built on a commitment to excellence, with unique guarantees and a high standard of service from day one. The team includes over 500 UK legally qualified writing experts, with many practising solicitors and barristers, and several former lecturers.","sameAs":["https:\/\/www.lawteacher.net","https:\/\/www.facebook.com\/LawTeacherNet","https:\/\/x.com\/LawTeacherNet","https:\/\/gravatar.com\/lawteacherprofile"],"knowsAbout":["Contract Law","Criminal Law","Constitutional and Administrative Law","EU Law","Tort Law","Property Law","Equity and Trusts","Jurisprudence","Company Law","Commercial Law","Family Law","Human Rights Law","Employment Law","Evidence","Public International Law","Legal Research and Methods","Dispute Resolution","Business Law and Practice","Civil Litigation","Criminal Litigation","Professional Conduct","Taxation","Wills and Administration of Estates","Solicitors\u2019 Accounts"],"url":"https:\/\/www.lawteacher.net\/author\/lawteacher"}]}},"_links":{"self":[{"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/posts\/5506","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/comments?post=5506"}],"version-history":[{"count":0,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/posts\/5506\/revisions"}],"wp:attachment":[{"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/media?parent=5506"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/categories?post=5506"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.lawteacher.net\/wp-json\/wp\/v2\/tags?post=5506"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}